Lee Wei Han Shaun

Lee Wei Han Shaun is a legal practitioner in Singapore. With documented cases from 2017 to 2024. The lawyer has handled 12 cases in Singapore's courts. Associated with 2 law firms. The lawyer demonstrates particular expertise in right of first refusal and inducement of breach of contract. Their track record shows a 50.0% success rate in resolved cases. They have managed 1 complex case, representing 8% of their total caseload.

Areas of Practice and Expertise

Lee Wei Han Shaun has demonstrated expertise across 80 primary practice areas, with significant experience in contract law and breach of contract.

Practice Area	Case Volume	Distribution	Expertise Level	Description
Contract Law	10 cases	9% of total caseload	Experienced62% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 10 cases which represents 9% of their total caseload.
Breach of Contract	6 cases	5% of total caseload	Experienced69% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 6 cases which represents 5% of their total caseload.
Contractual terms	4 cases	3% of total caseload	Experienced63% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 4 cases which represents 3% of their total caseload.
Arbitration	4 cases	3% of total caseload	Experienced72% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 4 cases which represents 3% of their total caseload.
Company Law	4 cases	3% of total caseload	General Practice43% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 4 cases which represents 3% of their total caseload.
Evidence	3 cases	3% of total caseload	General Practice40% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 3 cases which represents 3% of their total caseload.
Civil Procedure	3 cases	3% of total caseload	General Practice30% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 3 cases which represents 3% of their total caseload.
International Commercial Arbitration	3 cases	3% of total caseload	Experienced58% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 3 cases which represents 3% of their total caseload.
Right of first refusal	2 cases	2% of total caseload	Highly Specialized78% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 2 cases which represents 2% of their total caseload.
Performance Bond	2 cases	2% of total caseload	Experienced73% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 2 cases which represents 2% of their total caseload.
Damages	2 cases	2% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 2 cases which represents 2% of their total caseload.
Inducement of Breach of Contract	2 cases	2% of total caseload	Highly Specialized78% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 2 cases which represents 2% of their total caseload.
Recourse against award	2 cases	2% of total caseload	Highly Specialized94% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 2 cases which represents 2% of their total caseload.
Natural justice	2 cases	2% of total caseload	Highly Specialized78% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 2 cases which represents 2% of their total caseload.
Remedies	2 cases	2% of total caseload	General Practice48% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 2 cases which represents 2% of their total caseload.
Construction Law	2 cases	2% of total caseload	Highly Specialized90% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 2 cases which represents 2% of their total caseload.
Jurisdiction	1 cases	1% of total caseload	Highly Specialized75% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Construction	1 cases	1% of total caseload	Highly Specialized90% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Admissibility of evidence	1 cases	1% of total caseload	Experienced50% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Damages Assessment	1 cases	1% of total caseload	Highly Specialized75% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Setting aside	1 cases	1% of total caseload	Highly Specialized90% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
International Arbitration Act	1 cases	1% of total caseload	Highly Specialized90% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Liquidated Damages	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Income taxation	1 cases	1% of total caseload	Highly Specialized95% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Intention to create legal relations	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Agency Law	1 cases	1% of total caseload	General Practice30% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Reasonable Skill and Care	1 cases	1% of total caseload	General Practice45% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Breach of Duty of Care	1 cases	1% of total caseload	Experienced50% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Setting Aside Arbitral Award	1 cases	1% of total caseload	Highly Specialized95% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Appeals	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Summary Judgement	1 cases	1% of total caseload	General Practice30% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Crossclaims	1 cases	1% of total caseload	General Practice20% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Disclosure of documents	1 cases	1% of total caseload	General Practice15% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Peremptory orders	1 cases	1% of total caseload	General Practice10% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Interpretation of contractual terms	1 cases	1% of total caseload	General Practice40% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Appeal	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Performance of Contract	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Variation	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Interest	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Contracts (Rights of Third Parties) Act	1 cases	1% of total caseload	Experienced50% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Construction of Contract	1 cases	1% of total caseload	Highly Specialized80% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Contractors’ duties	1 cases	1% of total caseload	Highly Specialized90% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Extension of time and liquidated damages	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Delay in completion	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Failure to complete	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Scope of work	1 cases	1% of total caseload	Highly Specialized80% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Variations	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Back charges	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Interpretation of Contract	1 cases	1% of total caseload	Highly Specialized80% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Building and Construction Related Contracts	1 cases	1% of total caseload	Highly Specialized90% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Construction of Contracts	1 cases	1% of total caseload	Highly Specialized80% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Building and Construction Law	1 cases	1% of total caseload	Highly Specialized95% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Breach of Contractual Warranties	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Tort of Deceit	1 cases	1% of total caseload	General Practice30% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Wrongful Dismissal	1 cases	1% of total caseload	General Practice40% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Sale and Purchase Agreement	1 cases	1% of total caseload	General Practice40% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Apportionment of Liability	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Building Maintenance	1 cases	1% of total caseload	Experienced50% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Building Management and Strata Management Act	1 cases	1% of total caseload	General Practice40% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Disobedience of order of court	1 cases	1% of total caseload	General Practice30% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Auditing	1 cases	1% of total caseload	General Practice20% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Measurement contracts	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Employers’ duties	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Severance Payment	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Rectification Works	1 cases	1% of total caseload	Experienced50% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Banking and Finance	1 cases	1% of total caseload	General Practice20% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Building and Construction Contracts	1 cases	1% of total caseload	Highly Specialized95% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Business Litigation	1 cases	1% of total caseload	General Practice30% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Commercial Law	1 cases	1% of total caseload	General Practice10% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Commercial Real Estate	1 cases	1% of total caseload	General Practice10% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Employment Law	1 cases	1% of total caseload	Experienced50% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
International Arbitration	1 cases	1% of total caseload	General Practice40% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Personal Injury	1 cases	1% of total caseload	General Practice10% relevance score	Lee Wei Han Shaun has demonstrated general practice experiencein this area, handling 1 cases which represents 1% of their total caseload.
Insolvency Law	1 cases	1% of total caseload	Highly Specialized95% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Winding Up	1 cases	1% of total caseload	Highly Specialized95% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Minority Oppression	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Commercial Disputes	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Fraud and Deceit	1 cases	1% of total caseload	Highly Specialized75% relevance score	Lee Wei Han Shaun has demonstrated deep specialization and significant involvement in complex mattersin this area, handling 1 cases which represents 1% of their total caseload.
Conspiracy by Unlawful Means	1 cases	1% of total caseload	Experienced70% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.
Termination	1 cases	1% of total caseload	Experienced60% relevance score	Lee Wei Han Shaun has demonstrated substantial experience and regular engagementin this area, handling 1 cases which represents 1% of their total caseload.

Law Firm Affiliations

Lee Wei Han Shaun has been affiliated with 2 law firms. The most active affiliation involves 10 cases.

Law Firm	Cases Handled	Workload Share	Recent Cases
Bird & Bird ATMD LLP	10 cases	83% of cases	DHZ v DHY: Setting Aside Arbitral Award for Breach of Natural Justice and Jurisdictional Issues(Sep 2024) Keppel DC Singapore 1 Ltd v DXC Technology Services: Contractual Term Dispute over Data Centre Services(Jan 2024) ICOP Construction v Tiong Seng: Construction Dispute over Microtunneling Works(Jan 2024)
JWS Asia Law Corporation	2 cases	17% of cases	Bumi Armada v Tozzi: Right of First Refusal & Inducement of Breach of Contract Dispute(Aug 2018) Tozzi Srl v Bumi Armada: Right of First Refusal, Contract Formation & Breach(Sep 2017)

Case Complexity Analysis

Analysis of Lee Wei Han Shaun's case complexity based on the number of parties involved and case characteristics.

Complexity Overview

Average Parties per Case: 2.8
Complex Cases: 1 (8%); Cases with more than 3 parties

Complexity by Case Type

Type	Cases	Avg Parties	Distribution
Lost	33.4 parties avg	3.4	25%
Partial	32.3 parties avg	2.3	25%
Won	62.5 parties avg	2.5	50%

Complexity Trends Over Time

Year	Cases	Average Parties
2017	13.0 parties avg	3.0
2018	13.0 parties avg	3.0
2020	22.5 parties avg	2.5
2021	12.0 parties avg	2.0
2022	12.0 parties avg	2.0
2023	33.4 parties avg	3.4
2024	32.3 parties avg	2.3

Case Outcome Analytics

Analysis of Lee Wei Han Shaun's case outcomes, including distribution by type, yearly trends, and monetary outcomes where applicable.

Outcome Distribution

Outcome Type	Cases	Percentage
Lost	3(25%)	25%
Partial	3(25%)	25%
Won	6(50%)	50%

Monetary Outcomes

Currency	Total Amount	Average	Cases
CNY	1,885,630.00	1,885,630.001 cases	1
SGD	5,565,660.77	1,113,132.155 cases	5

Yearly Outcome Trends

Year	Total Cases	Outcome Distribution
2017	1 1	Won: 1 cases (100.0%)
2018	1 1	Partial: 1 cases (100.0%)
2020	2 11	Lost: 1 cases (50.0%) Won: 1 cases (50.0%)
2021	1 1	Won: 1 cases (100.0%)
2022	1 1	Partial: 1 cases (100.0%)
2023	3 12	Lost: 1 cases (33.3%) Won: 2 cases (66.7%)
2024	3 111	Lost: 1 cases (33.3%) Partial: 1 cases (33.3%) Won: 1 cases (33.3%)

Case History

Displaying all 12 cases

No.	Case	Decision Date	Party & Outcome
1	DHZ v DHY: Setting Aside Arbitral Award for Breach of Natural Justice and Jurisdictional Issues 15 Sep 2024 DHY (Respondent, Applicant)Won	15 Sep 2024	DHY (Respondent, Applicant): Application GrantedDHY's application to enforce the arbitral award was upheld as DHZ's application to set aside the award was dismissed.
2	Keppel DC Singapore 1 Ltd v DXC Technology Services: Contractual Term Dispute over Data Centre Services 11 Jan 2024 DXC Technology Services Singapore Pte Ltd (Defendant)Lost	11 Jan 2024	DXC Technology Services Singapore Pte Ltd (Defendant): Claim DismissedClaim dismissed against the Defendant; the judgment does not specify a currency, so SGD is assumed as the judgment originates from Singapore.
3	ICOP Construction v Tiong Seng: Construction Dispute over Microtunneling Works 01 Jan 2024 ICOP Construction (SG) Pte Ltd (Appellant, Plaintiff)Partial	01 Jan 2024	ICOP Construction (SG) Pte Ltd (Appellant, Plaintiff): Appeal allowed in partAppeal allowed in part. ICOP was awarded $489,064.89 for TSCE's delay in obtaining Authorities' Approvals and $255,360 for MTBM rental costs. (Assumed SGD, as the judgment originates from Singapore).
4	Voltas Ltd v Ng Theng Swee: Conspiracy, Deceit & Breach of Contract in Construction Subcontract 04 Sep 2023 Voltas Limited (Plaintiff, Defendant in Counterclaim)Won	04 Sep 2023	Voltas Limited (Plaintiff, Defendant in Counterclaim): Judgment for PlaintiffJudgment for the Plaintiff against the second defendant in the amount of S$3,437,937.36 (assumed SGD, as the judgment originates from Singapore).
5	Zhongshan Shengwang v Triple D: Breach of Contract & Intention to Create Legal Relations 29 Aug 2023 Zhongshan Shengwang Electrical Appliance Co Ltd (Plaintiff)Won	29 Aug 2023	Zhongshan Shengwang Electrical Appliance Co Ltd (Plaintiff): Judgment for PlaintiffJudgment in the sum of CNY1,885,630.00 to Shengwang. Interest at the rate of 5.33% per annum from the date of writ to date of judgment.
6	CUW v CUZ: Setting Aside Arbitration Award for Breach of Natural Justice 05 Feb 2023 CUY (Claimant)Lost	05 Feb 2023	CUY (Claimant): Application DismissedApplication to set aside the arbitration award was dismissed.
7	ICOP Construction v. Tiong Seng: Microtunnelling Dispute over Contract Termination and Delay Claims 11 Oct 2022 ICOP Construction (SG) Pte Ltd (Plaintiff, Defendant in Counterclaim)Partial	11 Oct 2022	ICOP Construction (SG) Pte Ltd (Plaintiff, Defendant in Counterclaim): Partial JudgmentPartial judgment in favor of the Plaintiff for SGD 1,333,298.52
8	Sun Electric Power v RCMA Asia: Winding Up Appeal Based on Insolvency 09 Jun 2021 RCMA Asia Pte Ltd (formerly known as Tong Teik Pte Ltd) (Respondent, Plaintiff)Won	09 Jun 2021	RCMA Asia Pte Ltd (formerly known as Tong Teik Pte Ltd) (Respondent, Plaintiff): Appeal UpheldAppeal upheld; awarded $50,000 in costs from the appellant (assumed SGD, as the judgment originates from Singapore).
9	Comptroller of Income Tax v Forsyth: Tax Appeal on Severance Payment 24 Nov 2020 Forsyth, John Russell (Respondent)Won	24 Nov 2020	Forsyth, John Russell (Respondent): WonThe respondent won the appeal.
10	Retrospect Investment v Lateral Solutions: Jurisdiction to Amend Consent Order After Discontinuance 05 Mar 2020 Retrospect Investment (S) Pte Ltd (Appellant)Lost	05 Mar 2020	Retrospect Investment (S) Pte Ltd (Appellant): Appeals DismissedAppeals dismissed; ordered to bear their own costs here and below. Assumed SGD as the judgment originates from Singapore.
11	Bumi Armada v Tozzi: Right of First Refusal & Inducement of Breach of Contract Dispute 05 Aug 2018 Tozzi Srl (formerly known as Tozzi Industries SpA) (Respondent, Plaintiff)Partial	05 Aug 2018	Tozzi Srl (formerly known as Tozzi Industries SpA) (Respondent, Plaintiff): Partial WinTozzi's claim for breach of right of first refusal was upheld in part, but the claim for inducing breach of contract against BAB was dismissed.
12	Tozzi Srl v Bumi Armada: Right of First Refusal, Contract Formation & Breach 20 Sep 2017 Tozzi Srl (formerly known as Tozzi Industries SpA) (Plaintiff)Won	20 Sep 2017	Tozzi Srl (formerly known as Tozzi Industries SpA) (Plaintiff): Judgment for PlaintiffJudgment for the plaintiff with damages to be assessed (assumed SGD, as the judgment originates from Singapore).